All 3 Peter Bottomley contributions to the Building Safety Act 2022

Read Bill Ministerial Extracts

Wed 21st Jul 2021
Building Safety Bill
Commons Chamber

2nd reading & 2nd reading
Wed 19th Jan 2022
Building Safety Bill
Commons Chamber

Report stage & Report stage
Wed 20th Apr 2022
Building Safety Bill
Commons Chamber

Consideration of Lords amendments & Consideration of Lords amendments

Building Safety Bill

Peter Bottomley Excerpts
2nd reading
Wednesday 21st July 2021

(2 years, 8 months ago)

Commons Chamber
Read Full debate Building Safety Act 2022 Read Hansard Text Read Debate Ministerial Extracts
Robert Jenrick Portrait Robert Jenrick
- Parliament Live - Hansard - - - Excerpts

As I understand it—I stand to be corrected if I have the wrong information—the 900 figure that the hon. Lady cites was a misinterpretation of the figures that were released earlier. None the less, the actual number is significant, albeit fewer than 900. We want to see waking watches used only in cases where they are absolutely necessary. The recent statement from the National Fire Chiefs Council has suggested that they are being used too often and that they can be reduced significantly. If she has constituents in that situation, as I am sure she does, in the first instance I would recommend that they make use of the waking watch relief fund to install a fire alarm, which can cut the costs very considerably.

This Bill takes an unusual step of retrospectively extending the period during which compensation for defective premises can be claimed—it more than doubles the current period, from six to 15 years. This significant step forward was requested and campaigned for by groups impacted by the cladding issue. We are going further, expanding the scope of the work for which compensation can be claimed also to include future major renovation work to buildings. These measures will not help everyone, but they do provide a step change in redress for raising issues. I hope that, in time, builders will extend their warranties to cover this period and provide the maximum amount of confidence to house purchasers.

Peter Bottomley Portrait Sir Peter Bottomley (Worthing West) (Con)
- Hansard - -

While my right hon. Friend is considering this point about the extension, will he please consider the point made by Robert Ayling, at Grosvenor Waterside, that the Building Act 1984 provision should be extended to six years after the plaintiff is aware of the defect? I am not asking for an instant answer, but such a measure would help to deal with the current situation very well.

Robert Jenrick Portrait Robert Jenrick
- Parliament Live - Hansard - - - Excerpts

I will give that further thought and revert to my hon. Friend on it.

It was clear after the fire at Grenfell Tower that action was required to address safety concerns with respect to existing buildings, and my predecessors rightly took a safety-first approach, as I have also tried to do. We have provided expert advice and accelerated inspections of all high-rise buildings, and that work continues, with substantial progress having been made by the National Fire Chiefs Council on the building risk review, which is likely to be concluded by the end of the year. We have provided £5 billion in grant funding to carry out vital remediation work targeted at the buildings we know to be at the greatest risk from fire spread—those over 18 metres—and we have banned the use of combustible materials on the external walls of high-rise residential buildings, providing industry with a clear standard for the construction of new builds.

Some 474 buildings have been identified as having Grenfell-type ACM—aluminium composite material—cladding. We are now well on the way to remediating all of those buildings. Over 95% of the buildings identified at the beginning of last year have either completed or started remediation work; 70% of those have now been fully remediated, and that is rising every week. That means that around 16,000 homes have been fully remediated of unsafe ACM cladding, an increase of around 4,000 since the end of last year. Despite many building owners failing to provide adequate basic information, almost 700 buildings with other types of unsafe cladding are proceeding with a full application to the building safety fund. We have already allocated £540 million, which means that owners of 60,000 homes within high-rise blocks can be reassured that their remediation will be fully funded.

We currently forecast that over 1,000 buildings with non-ACM unsafe cladding will receive support of the same form through the building safety fund, providing a guide to the cohort of high-rise buildings where remediation is actually required. That is being progressed by a dedicated team in my Department and our two delivery partners, Homes England and the Greater London Authority. The Government have played their part: the unprecedented £5.1 billion we are providing gives assurance to leaseholders in eligible buildings that unsafe cladding on their blocks will be replaced at no cost to them.

I know that there will be strong feelings across the House about industry needing to fix and pay its fair share for problems that is has helped to cause. I recognise that some house builders have stepped up, too, thus far committing over £500 million for remediation since my statement in February. But some have not stepped up, or at least not in the way I expect them to. Ballymore, for example, has yet to commit to fully funding the remediation of its buildings.

The industry needs to go further. That is why we are introducing a new levy on high-rise residential buildings. We have published today a consultation document on the levy and I welcome views from all interested parties on its design. The levy will sit alongside a tax being developed by the Chancellor to raise at least £2 billion to contribute to the costs of historical remediation. This Bill also introduces the building safety charge to provide residents with clarity and certainty on the costs of building works, and we have listened and ensured that that charge only includes the cost of management of building safety in their building.

As I said at the outset, in bringing forward this new building safety regime we need to take a sensible, proportionate approach driven by expert advice. The Bill ensures that the building safety regulator will regulate in line with best practice principles, be proportionate and transparent, and ensure that the interests of leaseholders are protected. In 2020, only 9% of fires were in flats of four storeys or more. In 2019-20, only 7% of fires spread beyond the room of origin in such buildings. And, while every death is of course tragic, thankfully only 10 people died in 2020 as a result of a dwelling fire in flats of four storeys or more. We strongly believe that our proportionate approach is in line with these facts, ensuring that remediation works are undertaken only where absolutely required, and leaseholders should not be landed with bills for unnecessary work.

Unfortunately, that is not the position today and we need a significant reset. Too many people living in lower and medium-rise buildings have told us of feeling trapped in their properties, held back from selling their homes because of excessive caution in the lending, surveying, insurance and fire risk assessment markets. Understandably, this has caused residents to worry over safety and has led to unnecessary costs. I want to be clear that the vast majority of residents in all homes in this country, including blocks of flats, should not feel unsafe. Driven by these concerns, earlier this year I asked a small group of experts on fire safety to consider the evidence and advise me on the steps that should be taken to ensure a proportionate, risk-based approach to fire safety in blocks of flats. I thank them for their time and their expert advice, which I will publish later today.

The key finding of the experts’ advice is clear: we cannot and should not presume systemic risk of fire in blocks of flats. I quoted some of the statistics earlier, but let me repeat them. Dwelling fires are at the lowest point that they have been since we started to collect comparable statistics in 1981, despite the fact that in 2020 people spent significantly greater amounts of time in their homes as a result of covid restrictions. On that basis, the expert advice includes five significant recommendations to correct the disproportionate reaction that we have seen in some parts of the market. First, EWS1 forms should not be a requirement on buildings of less than 18 metres.

--- Later in debate ---
Eleanor Laing Portrait Madam Deputy Speaker (Dame Eleanor Laing)
- Hansard - - - Excerpts

I thank the hon. Gentleman for what I consider to be properly a point of order. The Secretary of State has most courteously explained to the House that the statement that is now forthcoming is market sensitive. I have had a chance to glance at it and I understand that it is indeed market sensitive, so I can understand, and I think the whole House will now understand, why the Secretary of State issued it at the point that he did.

I have to say to the House that there seems to have been some delay in the Vote Office and in the workings of the House, and for that, on behalf of the House authorities, I apologise to Members and to the Secretary of State. I thank the Opposition Whips for giving me a copy, since nobody else did—

Eleanor Laing Portrait Madam Deputy Speaker
- Hansard - - - Excerpts

I am still finishing my response to the point of order, Sir Peter.

I think there are some points in the statement that the Secretary of State will wish to clarify. I am not putting a time constraint on him, as I normally would, for finishing his Second Reading speech, because in addition to that speech it would be appropriate for him to take two or three questions on his written statement.

Peter Bottomley Portrait Sir Peter Bottomley
- Hansard - -

Further to that point of order, Madam Deputy Speaker. The written statement has the number HCWS228; an online search brings up one with a similar number from January 2015. Could the House authorities see whether they can get the statement online so that those Members who are participating virtually also have the chance to read it?

Eleanor Laing Portrait Madam Deputy Speaker
- Hansard - - - Excerpts

I thank the hon. Gentleman for that point of order and I reiterate it. I wonder whether the House authorities have done that—I do not know but I ask them to do so immediately.

--- Later in debate ---
Peter Bottomley Portrait Sir Peter Bottomley (Worthing West) (Con)
- Hansard - -

Thank you, Madam Deputy Speaker, and welcome.

Paragraph 19 of the National Audit Office report says:

“The Department has acknowledged that only in a minority of cases would it be financially justifiable for building owners to bring legal action to recover money.”

But the building owners will only make a claim if they are indemnified by the residential leaseholders, who do not have the money, so it is not going to happen, and the sums that the Department has reclaimed are very low. What is clearly obvious is that they will not get money from leaseholders. That follows on from the report of a working party set up two weeks after the Grenfell fire by Ted Baillieu, the former Premier of Victoria in Australia, and an architect. It reported within two years. He gave a presentation to the all-party fire safety group and the all-party leasehold and commonhold reform group. As they will not get money from leaseholders, they have to find the problems, fix the problems, fund the problems and then see how to get the money back. We know that the Ministry of Housing has got just over £5 billion from the Treasury. It expects to get perhaps £2 billion back in tax and £2 billion back in levy. If £15 billion is spent, there will be £3 billion back in VAT. So the Treasury seems to make money out of this, and who is left with the £10 billion of funding? The residential leaseholders, who cannot afford it.

It is quite clear that the Government have to do two things: first, as I said to the Secretary of State during his speech, extend the Building Act 1984 so that people can make a claim within six years of knowing that there is a problem; and secondly, make sure that the insurance industry knows that it is ultimately liable for what the architects, designers, component suppliers, builders, regulators and building control groups have done and must get most of the money back by agreement. There is no point in having individual leaseholders, or groups of them, taking legal action; it will not work. I say to the Secretary of State: in this case, please listen to those who know and try to make sure that no examination takes place without leaseholders being part of the committee. They could have told the Secretary of State four years ago that his approach was not working.

We are grateful for some progress, but we need much more.

Building Safety Bill

Peter Bottomley Excerpts
Matthew Pennycook Portrait Matthew Pennycook
- Hansard - - - Excerpts

My hon. Friend makes a very good point, which she has made in other debates in this place with regard to unscrupulous developers operating in her constituency. Changes to company law certainly warrant further consideration in that respect.

Peter Bottomley Portrait Sir Peter Bottomley (Worthing West) (Con)
- Hansard - -

May I add the problem that leaseholders do not have an interest in a brick of their building and that a claim would need to be made on their behalf by the freeholders to the landlord, who would require indemnity costs from the leaseholders who cannot pay?

May I, through the hon. Gentleman, suggest to the Government that between now and the House of Lords they consider taking a right to take the potential claims by the landlords on behalf of leaseholders into a public agency which can make a public claim against the developers, builders, architects, surveyors, building specification and building controllers, so that money can be brought back from those who were responsible, not the innocent leaseholders who are not?

Matthew Pennycook Portrait Matthew Pennycook
- Hansard - - - Excerpts

I thank the Father of the House for that intervention. That is a very good suggestion, which I hope the Minister will take on board and give some considered thought to.

Notwithstanding our concerns with regard to the limitations of the Defective Premises Act, we argued forcefully in Committee for the Bill to be revised so that the period for claims under the 1972 Act be extended from six to 30 years, rather than from six to the 15 years the Government proposed. In response, the Minister urged my hon. Friends to withdraw our amendment on the grounds that a 15-year limitation period was appropriate and indeed that any further retrospective extension beyond 15 years would increase the chances of the legislation being tested against the Human Rights Act and found wanting. Because that argument was never convincing, we are extremely pleased that the Government have reconsidered their position on this matter in the light of the case made by my hon. Friends in Committee, and have brought forward amendments 41 and 42, which provide for that 30-year limitation period, as well as changes to the initial period. We fully support both amendments.

We also believe that new clauses 11 and 12, proposed by the hon. Members for Stevenage (Stephen McPartland) and for Southampton, Itchen (Royston Smith), warrant support. If the Government genuinely believe that litigation has a significant part to play in helping to fix the building safety crisis, they need to give serious consideration to permitting a limited class of claims relating to pure economic loss, rather than just actual physical damage.

Clauses 129 to 134 concern the new homes ombudsman scheme, the creation of which we support, albeit, as the Minister will know, with some concerns about its operational independence and the composition of the new homes quality board. While we remain unconvinced that the new ombudsman and the new code will lead to a step change in developer behaviour and thus a marked increase in the quality of new homes, we see no issue with the scheme being expanded to cover Wales and Scotland, so we support the various Government amendments to that effect under consideration today.

Finally, I want to turn to amendments relating to the fundamental and contentious issue of leaseholder liability. I know I need not detain the House for any great length of time on why it is essential that greater legal protection for leaseholders be put on the face of the Bill.

--- Later in debate ---
Stephen McPartland Portrait Stephen McPartland
- Hansard - - - Excerpts

I completely accept that point, and the hon. Member will know that we are all in the same position. Every single community is affected up and down the country; there are millions of leaseholders.

The new approach that the Government are taking mirrors a lot of what we want in our amendments on these issues. For example, a number of the amendments I am going to speak to refer to redress. We asked for a period of 25 years, and the Government have come forward with 30 years. We asked for the time in which someone can make a claim to be extended from 90 days to two years, and the Government have come forward with one year. That demonstrates the communication going on behind the scenes and what we are trying to do to deliver success for leaseholders. In some ways, it does not really matter what our opinions are in this place; what matters is what we deliver for those millions of leaseholders up and down the country, so that they do not face bankrupting bills and huge mental health issues.

Peter Bottomley Portrait Sir Peter Bottomley
- Parliament Live - Hansard - -

Without the calm persistence of my hon. Friend and our hon. Friend the Member for Southampton, Itchen (Royston Smith) in this parliamentary year and the one before, we would not have got this far and, on behalf of 1 million leaseholders in all parts of England and Wales, may I say that we are grateful for their efforts? Will they please keep going?

Stephen McPartland Portrait Stephen McPartland
- Hansard - - - Excerpts

I am very grateful to the Father of the House, and I would like to thank the cladding groups up and down the country, such as End Our Cladding Scandal UK, the UK Cladding Action Group and the Leasehold Knowledge Partnership. I record my thanks to the Father of the House and all my colleagues on both sides of the House who have done everything they can to get us to a position where we are working together to secure something that is in the best interests of leaseholders. The way in which the tone has changed, as all of us who have been working on this Bill have seen, and the way in which we now feel we can give the Government room to try to improve the Bill, give us great hope.

A number of the amendments—new clauses 4 to 13 —are specific technical amendments to give the Government examples of how we could fix the problem. The Government have tabled 70 amendments, but of course they still have to come forward with the amendments that we want in the Lords, otherwise the Bill will come back to this House and we will be in the same position, so I think it is important that we continue our efforts.

One of the issues facing leaseholders was the real frustration that VAT is levied on some of the costs. We are asking for the VAT to be scrapped, because when the Treasury puts forward £5 billion, £1 billion of it will be going back to the Treasury automatically; the frustration is understandable. Another example we give is how a previous defects Act—the Defective Premises Act 1972—could be used, as it was for properties with prefabricated concrete. The legislation exists, and these leasehold properties could be incorporated in it. There are a variety of other amendments on technical points, and they are the means of giving the Government examples of how we can support leaseholders.

There is a huge opportunity with new clauses 4 to 13 for the Government to think a little further outside the box. For example, I have a property in my constituency, Vista Tower—one of the famous properties—where the remediation costs are £15 million for 73 flats. The leaseholders paid £200,000 for their flats, and their remediation costs are £212,000, so hon. Members can understand what we are doing and why we originally got involved in this debate. Those people are beyond bankrupt. The mortgage companies are losing money, and that was before the leaseholders got into paying over £300,000 for waking watch and all the other interim costs that have added to the bills.

The Government have come with us and are working in a place where we can try to fix the problem, but there is still a lot more to do. Collectively across the House, we have to find a way forward. For that particular property, with the announcement that the Secretary of State made, leaseholders’ costs went from £200,000 down to £60,000. If we can get commitments from Ministers to include internal developer-responsible fire safety defects such as missing firebreaks, where the developers illegally constructed the building, leaseholders’ costs will collapse again.

I keep asking the Minister every time he looks at me, speaks to me or walks past me whether he will commit to protecting leaseholders in law with his amendments in the Lords. Obviously we all want that, and it is what leaseholders want, because we want to be in a position legally where we can say to a management company or freeholder, “You can’t charge them for this, and you can’t tell them”—as the hon. Member for Carmarthen East and Dinefwr (Jonathan Edwards) has referred to—“that they’ve got 28 days to make this payment.” That is ridiculous, and it is not fair. The Government are working with us and listening to us, but there is a lot more work to do. I would like to continue working with the Government to ensure that we get out there and protect leaseholders.

Madam Deputy Speaker is now staring at me, so I shall bring my remarks to a swift conclusion. I would like to thank everybody who supported us throughout the campaign. We are not there yet, but we are very close to getting there and supporting millions of constituents up and down the country. I will not be pressing my amendments.

--- Later in debate ---
Mike Penning Portrait Sir Mike Penning
- Parliament Live - Hansard - - - Excerpts

I do not think there is a conflict, but I refer to my entry in the Register of Members’ Financial Interests. As an ex-fireman, although my concerns and thoughts are with the victims of the Grenfell fire and their families and loved ones, I say that we must put on the record our thanks to the emergency services, and particularly the firefighters, who have to live with what they saw—most of them will never have seen such an incident in their life. They went in one direction while, quite understandably, the public went in the other.

I do not disagree with anything I have heard in the House today. My constituency neighbour, the hon. Member for St Albans (Daisy Cooper), and I are as one. If this is not sorted in the other House, as promised, we in this House will sort it. That is not a threat but a promise. The Minister, the Secretary of State and the Prime Minister, as we heard, have been brilliant in changing direction. They realised the risk that no thought at all had been given to leaseholders.

I declare an interest because my daughter has a leasehold property. When she bought it, why would she have dreamed that this situation would occur and she would face such penalties?

When I intervened on the Minister, I said I would mention a way out. Those hon. Members who have been here long enough will remember that I took the Mesothelioma Act 2014 through this House. The Act compensated people whose lives, through no fault of their own, had been devastated by asbestos. We could not fine the insurers, the companies, the directors or the shareholders, so they had suffered and they had not got compensation. This Bill is an opportunity to resolve the problem for leaseholders where we cannot impose fines.

There is no reason why leaseholders should drag themselves through the courts. We are trying to sort the matter out in this House. We should put a levy on the insurers. Without any doubt, the insurers got the premium from these companies, because otherwise they would not have been allowed to build the properties, so liability insurance was in place. The fact that we cannot find the developers—some have gone offshore in parts of my constituency—is irrelevant now. If we can find them, fine, but if not, we will levy the insurers.

We do not need to reinvent the wheel. We have already done it with the mesothelioma Bill. Originally, we gave the victims 80% of the compensation that they would have got through the courts. Eventually, we gave them 100%. This House was unanimous in its support of the Bill as it went through its stages. It was probably one of the easiest Bills that I have taken through the House—apart from having to pronounce mesothelioma, which, to this day, still troubles me, as Members may have notice.

This is an option that I have mentioned to the Minister before. I have said that his civil servants can come and talk to me, or to anybody at the Department for Work and Pensions who took that legislation through. I am more than happy for that to happen. Sadly, though, no one has talked to me about this—I am gently looking towards the civil servants in the Box, which I am not meant to do. This is a great opportunity to right a wrong that we can see coming down the line here.

Peter Bottomley Portrait Sir Peter Bottomley
- Parliament Live - Hansard - -

Were claims to go through the courts, they would be aimed at the developers, the builders, the architects, the surveyors, the component suppliers, the building controllers and the building regulations specifiers, all of whom were insured or operating under Government. We need to get them altogether around the table and say, “What will be the total liability?” We would save the lawyers’ costs and get the money in very fast. Leaseholders will be protected. Their homes will be safe and they will be saleable.

--- Later in debate ---
Peter Bottomley Portrait Sir Peter Bottomley
- Parliament Live - Hansard - -

To use the words of a former Prime Minister, I agree with Matthew. I thank the hon. Member for Greenwich and Woolwich (Matthew Pennycook) for his contribution to Third Reading, and thank the Minister, who over the months has moved progressively—if I may use that expression in relation to a Conservative—to do many of the things that, frankly, ought to have been done within months of Grenfell, if not before.

I have two major regrets. One is that the reaction to Grenfell was to make it party political, even though most of the 12,000 buildings affected were not built by Tory councils and have problems just as great as those at Grenfell. The second, which is a different point, is that when the sad crash in the tunnel in Paris, in which three people died and one survived, occurred, the media, instead of saying on the first day that the survivor had been wearing a seatbelt and the three who died had not and that the driver was twice over the legal limit, allowed that point to be lost behind the paparazzi story. If the truth had come out straight away, the number of deaths in Europe over the next year would have been halved.

In terms of fire safety and building safety, in my view it was wrong to say that 18 metres was the cut-off point. It may have been arbitrary that that was the highest level the fire could get to, but analysis of the risk to people in homes is that most deaths are at lower heights, not higher ones. We have also learned lessons on dealing with fires that will not be forgotten.

The Bill goes a long way to meeting some of the needs that were reasonably obvious at the beginning. The underlying problem is that Dame Judith Hackitt was not, I think, properly briefed on the law on residential leasehold, and that caused the mis-steps that are now beginning to be put right. I hope that as a result of the Secretary of State’s consultations with people such as Philip Rainey and other barristers and solicitors who are expert in this field, we will be able to modify the simple polluter pays principle into a practical measure.

We need to stop homes being lethal. We need to stop legalities getting in the way of justice and effective action. We want to take away the financial burden and nightmare from residential leaseholders. We want to make sure that social landlords are not left with the costs that, frankly, should not be theirs. We have a lot more progress to make. It is a matter of faith in the Government that, together with the amendments made today—I congratulate the parliamentary draftsmen and the officials in the Department on the progress they have made so far—we can hope to see further progress and better amendments and supplementary ones tabled in the House of Lords, which can come back here and be both successful and acceptable.

I have two further points for the Minister. Outside this Bill, we look forward to the Law Commission reforms being put to Parliament in an effective way. Last, on the question of forfeiture, which has come up occasionally in today’s debates, I want there to be no question that a leaseholder’s equity should be forfeited just because their home is sold to pay some debt. We must change the law to say that any remaining equity goes back to the leaseholder and is not put in the hands of the landlord. William the Conqueror was king over 950 years ago. His feudal memory should not be continued in our housing system. It is time to enact in practice provisions that the House of Commons passed in law—ineffectively—in 2002. Let us have justice for residential leaseholders.

--- Later in debate ---
Stephen McPartland Portrait Stephen McPartland
- Parliament Live - Hansard - - - Excerpts

I am grateful for the opportunity to speak on Third Reading. I am hopeful this evening and, like many Members from all parties, I am grateful to my hon. Friend the Member for Southampton, Itchen (Royston Smith), to the Father of the House, my hon. Friend the Member for Worthing West (Sir Peter Bottomley), and to colleagues across the House who have worked so hard to get us where we are today.

This is a huge Bill that tries to deal with some of the after-effects of the tragic events at Grenfell Tower. I have been to meet residents at New Providence Wharf, who have also had a very difficult time. Some of the issues they have had are heartbreaking and it is incredibly difficult to speak to them and hear what they have been through. We talk about fire safety in this place, but meeting people who were involved in fires and who were trapped in properties really brings it home.

I understand why the Government want to bring the Bill forward as quickly as they can. They have tabled 70 amendments and I understand their desire to work with Members across party lines to get to a much better place in respect of the bits we want. Although it is a very large Bill, a lot of us in the Chamber are focused on a small part of it: the provisions on leaseholders and leaseholder protections. That is the bit on which my colleagues and I mainly focus. It is important for me and for leaseholders up and down the country that they are not held responsible for historic fire safety defects and construction defects.

Let me remind the House where we have come from. When we started our campaign about 18 months ago, the Government’s original offer was around £20 million to deal with these issues. After the statement from the Secretary of State last week, we are now on course to have more than £9 billion of Government support, with probably another £100 million for waking watch, alarms and a variety of other issues. The Government have moved forward massively.

I do not always support the Government but, in fairness to them, on this issue we have asked and they have negotiated. There is a new tone and a new willingness to work both across party lines and within the governing party to resolve this issue for leaseholders, so we have hope. Tonight, millions of leaseholders up and down the country, many with huge mental health issues and facing massive financial ruin, have hope. That hope encourages us to believe that we may finally come to a position where we can resolve things for those millions of leaseholders.

We are in the position we are in because, although a lot of people will not realise this, the Prime Minister has intervened directly on a number of occasions to get us to a state in which we can support each other, negotiate and get more than £9 billion-worth of support for leaseholders, which is an amazing achievement. I am delighted with the work we have done behind the scenes to get us to where we are. Because of that hope and the constructive way in which the Government have worked with us behind the scenes, we want to give them the room to work with us a bit further and to table amendments in the House of Lords to protect leaseholders in law. That is what we want—that is our first request.

The second request that I continue to make is that amendments are made to protect leaseholders in respect of internal fire safety defects and not just external ones. At Vista Tower in my constituency, which has more than £15 million-worth of remediation costs, the fire breaks are missing. They would have been in the plans and signed off by the developers and the building regulatory regime, but they are missing. We have to think about how we can support constituents like that.

Peter Bottomley Portrait Sir Peter Bottomley
- Hansard - -

Will my hon. Friend allow me to add to what he is saying? The insurance companies are claiming premiums that are 10 or 20 times higher than before because there are additional fire risks. All this work should lead to reduced fire risks. Will he support me in asking the Government to get together with the technical sides of the insurance companies and the Competition and Markets Authority to get those insurance premiums back down to what they were before so that leaseholders may pay £300 a year to insure a building they do not own rather than £3,000 a year?

Stephen McPartland Portrait Stephen McPartland
- Hansard - - - Excerpts

I completely support the Father of the House, as he knows, in all matters.

It is important that the Government have accepted the principles of everything that we have asked for throughout this 18-month campaign. I am very grateful for that. With all the technical details, that campaign has demonstrated how complicated this issue is and the many millions of people and tens of thousands of buildings it affects in many different ways. In fairness to the Minister and the Government, it is very difficult to put all that into a Bill, so they do need time. As long as they are prepared to work with us, we are prepared to give them that time so as to support leaseholders and ensure that they do not have to pay for these historical fire safety defects.

I have one final request for the Minister on behalf of those constituents of mine in Vista Tower who have been affected by the building being no doubt shoddily built and not to the plans of the time. Will the Government be prepared to provide support so that those leaseholders can take action against the original developers, or will the Government take the action on their behalf, because a lot of these leaseholders have been going through this for a number of years and no longer have the mental resilience or ability to take these fights on and take legal actions for the next five or 10 years in the courts? Will the Minister provide further support to those leaseholders? Will he agree to continue to meet and work with me so that we can ensure that leaseholders are not held responsible and they are the innocent parties throughout this crisis?

Building Safety Bill

Peter Bottomley Excerpts
Consideration of Lords amendments
Wednesday 20th April 2022

(1 year, 11 months ago)

Commons Chamber
Read Full debate Building Safety Act 2022 Read Hansard Text Read Debate Ministerial Extracts Amendment Paper: Commons Consideration of Lords Amendments as at 20 April 2022 - (20 Apr 2022)
In no way does this Bill represent a comprehensive solution to the building safety crisis—not least because that will depend on a range of non-statutory Government interventions and the agreement, voluntary or otherwise, of banks and insurers—but it has been strengthened in important ways in the other place. Instead of seeking to unpick a number of those improvements, the House should vote to retain them. I urge Members on both sides of the House to join us in the Division Lobby later today to ensure that that is the case.
Peter Bottomley Portrait Sir Peter Bottomley (Worthing West) (Con)
- Parliament Live - Hansard - -

I thank my hon. Friend the Minister for the way he introduced the amendments, and I thank the Labour spokesman, the hon. Member for Greenwich and Woolwich (Matthew Pennycook), who spoke in a non-party way about the matter. I pay tribute to those on both sides of the House who have been working on the Bill, often without proper recognition. Among them I include the hon. Member for Sheffield South East (Mr Betts), the Chair of the Levelling Up, Housing and Communities Committee. Its first report on the leasehold disaster was critical to getting Government and some people outside to pay attention.

If anyone from a major media organisation is listening, I urge them to make sure that they have a housing editor who can pay attention to this issue and provide continuity. During the four or five years since Grenfell, several people have taken up the issue of the fire itself, but no one has provided the necessary continuity when it comes to television and radio programmes. Institutional memory is required if we are to understand how we got to where we are, and where we need to get to. For residential leaseholders, fair, detailed, expert housing coverage matters as much as coverage of health, economics, defence and other things. I commend to media organisations the idea of having a housing editor and a team who can help us to do our work better, because without media reflection of our efforts, we will not go as far or as fast as we ought to.

Bluntly, the thinking in the Treasury has been the cause of much of the delay. The tragic deaths at Grenfell, where over 70 people died unnecessarily, were a spur to action. For too long, however, people said, “Look at the Royal Borough of Kensington and Chelsea; this is all its fault.” Most of the blocks affected are not in Chelsea or in Conservative-controlled areas, so we all have a responsibility to accept that we got things wrong.

What was needed to get this right? It was best put by Ted Baillieu in Victoria, Australia, who said that it was necessary to find the problems, fix the problems and fund the problems, and then get after the people who are responsible. If we had done that, for the last four years many more innocent residential leaseholders would have been able to live in homes that they knew to be safe and saleable, and we would be many steps further forward.

I hope that my hon. and right hon. Friends in the Department for Levelling Up, Housing and Communities want to make sure that no block is left unremediated—in plain English, to make sure that every block is made safe—and then go after the money, but the Treasury is blocking that.

I put this question to my hon. Friend the Minister. Who will take claims against those other than the developers—the architects, the surveyors, the component manufacturers, the people who set the building standards and the people who did building control, whether in the public or private sector—who were involved? I am not saying that they are all responsible, but some are. In any other field, lawyers would be coming forward with a class action to put them all in the dock and claim from them the costs that would otherwise fall on innocent residential leaseholders.

For those who are new to this, I repeat that the only people who are totally innocent—the only people who do not own a single brick in the building—are the residential leaseholders, and yet they are being left with some of the costs. If it comes to Divisions, I will vote in a non-party way to try to keep the intentions of the House of Lords going on most of the issues.

I do welcome and accept what the Minister said about extending to three years the responsibilities of the Building Safety Regulator. That makes sense, given the timescale, but what is controversial is leaving residential leaseholders with some of the costs. I draw the House’s attention to the fire at Gibson Court in Woking in 2011. Six years later, those responsible were fined more than £300,000 because their fire protection work had been clearly inadequate. In that case, part of reason for the spread of the fire was the fact that lofts went right across the buildings.

I also draw the House’s attention to the point that the hon. Member for Greenwich and Woolwich made about the fire in 2019 at Worcester Park, where 23 other blocks had to be made safe because one block went up in smoke in 11 minutes. If a fire can spread so far in that many minutes, the idea that it could be contained within one flat is not realistic; those who are vulnerable would have no chance of getting out safely.

I hope that this Bill has the power, under secondary legislation, to extend provisions on remediation costs to buildings below 11 metres, especially for the vulnerable, although I would prefer it to go as far as the House of Lords wanted, so that leaseholders do not have to pay.

Remember that a few years back, Government appeared to be thinking that costs of £15 billion could fall on these residential leaseholders, who did not have the money. I am not talking about people who live in big, expensive, multi-million-pound apartments looking out over the Thames. I ought, by the way, to declare an interest, as I have a small flat in Worthing, which does not even look out over the sea. Six of us bought the freehold and we have had no problems with this, or even with managing agents or insurance companies. I will be buying a leasehold on another property in London in time, and I hope it will not be affected either. I put that on the record, just in case someone says that I am talking from self-interest.

I am speaking in the interest of people who are poorer than I am, who live in homes that are less valuable than mine, and who have been lumbered with all the disadvantages of being a residential leaseholder—and now with this fire safety defect issue as well.

I reinforce what other hon. Members have said about insurance. Premiums are unreasonably high; I hope that the Competition and Markets Authority and the Financial Conduct Authority will quickly produce a report, and that publicity will make insurance companies bring rates down to market rates—that is to say, rates that are justified by the risk, not by what the market can be made to pay in a crisis. I also hope that all commissions, rebates and douceurs—sweeteners—paid by brokers or insurance companies and received by managing agents or landlords are disclosed. That ought to be out in the open.

For too long, too many people have got rich on the back of residential leaseholders. There are many more things that I would like to say, but I suspect that, given the amount of interest in the subject, I ought to stop now. As well as thanking those from both sides of the House who have worked on this, I thank the National Leasehold Campaign. Without it, we would not have had Victoria Derbyshire’s interest, which has been important. I thank the cladding groups, in all their manifestations. At great expense to themselves, and having given up some of their other responsibilities, they have brought these issues to the attention of Parliament.

I also thank officials in the Department, because after a very slow start, a group of people has been brought together to support Ministers in their legitimate aim of making sure that those who are responsible pay, and those who are not responsible do not have to.

Clive Betts Portrait Mr Clive Betts (Sheffield South East) (Lab)
- Parliament Live - Hansard - - - Excerpts

It is a pleasure to be able to speak in this debate. I thank the Father of the House, the hon. Member for Worthing West (Sir Peter Bottomley), for his kind words about the Select Committee. He certainly encouraged and prodded us to do the first report on leasehold reform. It was, as he said, a first step towards what we hope will eventually be much more significant reform, which I think the Government are committed to.

Since the tragedy of Grenfell, the Select Committee has produced five reports. I am pleased that the hon. Member for Harrow East (Bob Blackman) is in his place, because he has been with us right the way through those reports, all of which were agreed unanimously by the Select Committee. We have repeated over and over again that leaseholders who are not responsible should not have to pay, and neither should social housing tenants; they are no more responsible, and the two should be seen together and treated equally.

I am pleased with what the Minister said today. I hope it was not just a way to get the debate over with, without pushing away too many difficult questions, and that he is still prepared to look at broadening the scope of the Government’s offer to leaseholders and to social housing landlords and tenants. If that was a genuine offer and he is keen to work on it, that is welcome.

We clearly have come quite a long way since the first offer of a £400 million package to deal with ACM cladding. That was going to solve everything, but obviously it was not, even when the Chancellor stood up and offered in his Budget the £1 billion building safety fund and said that was going to give everything the Select Committee had asked for, which it was not and did not. We have moved on since then, so it is welcome that we have now got to a better place, although it is still not quite good enough.

--- Later in debate ---
Lastly, although I paid tribute to the Government, they have created a highly complex edifice, which has been described, I think by the Leasehold Knowledge Partnership, as a waterfall, because lots of things have to happen in the right order for the scheme to work. I understand why the Government have done that—because they are determined to go after the people who are in fact responsible for the scandal—but it means that uncertainty will continue for our constituents while they wait for all this to work.
Peter Bottomley Portrait Sir Peter Bottomley
- Hansard - -

The right hon. Gentleman mentioned the Leasehold Knowledge Partnership, which I should have included in the list of those to be thanked. I think that representatives of the partnership and the National Leaseholders Campaign have had time to get from the rally to the Gallery, so I repeat the thanks to them. I include with them Lord Greenhalgh, who has engaged with all the voluntary groups. I can think of no better aim for a campaigning charity than saving residential leaseholders from a situation from which they could not otherwise escape.

Hilary Benn Portrait Hilary Benn
- Parliament Live - Hansard - - - Excerpts

I am delighted to echo the Father of the House. The partnership has been brilliant in its analysis of what has and has not been done, what the problems are and what the solution ought to be, and it has also been persistent.

I know the Minister will appreciate my final point, because he has worked very hard on this. Our constituents have waited long enough, with their lives on hold, and the sooner we can made all these bits work, the better. We have to enable them to wake up in the morning and think, “D’you know what? I don’t have to worry about the nightmare I’ve been living in for the last five years and I can get on with the rest of my life.” We owe it to them to bring the day they dream of around as soon as possible.

--- Later in debate ---
Royston Smith Portrait Royston Smith
- Parliament Live - Hansard - - - Excerpts

I refer hon. Members to my entry in the Register of Members’ Financial Interests.

I thank the Secretary of State, the Minister and the Department for what they have done to get us to this stage. I also pay tribute to the cladding groups, which have acted with great integrity and determination. If they are not completely content today, at least they are in a much better place than they were during the passage of the Fire Safety Bill.

That Bill now seems quite a long time ago, but that is nothing compared with how long it has felt for the leaseholders who are still caught up in this awful scandal. We were promised at the time that the Building Safety Bill would deal with the issues of leaseholders having to pay. It seems that the Government have been as good as their word and have made sure that at least leaseholders will not be held responsible—we all know that they are the only people in the entire situation who are not responsible. I was cynical when the Government said that they would deal with the issue in the Building Safety Bill, so I am particularly happy. Of course, I was not nearly as cynical as the leaseholders who were facing bills for tens of thousands of pounds and were wondering whether the issue would just be kicked down the road and into the long grass. I am pleased that at least we are now somewhere that we can all be a lot happier.

The Bill is infinitely better than what we have seen before and is definitely a move in the right direction. I have mentioned to the Minister, who has made himself available numerous times now, my concerns about buildings under 11 metres. I think it was the Chairman of the Select Committee on Levelling Up, Housing and Communities, the hon. Member for Sheffield South East (Mr Betts), who said that if a building were 1 cm lower than it needed to be, that could be the most expensive centimetre in history. That is exactly the point: some of these numbers are a bit arbitrary.

What the Minister has said at the Dispatch Box has given me some comfort—enough comfort, as it happens, to support the Government today. Going forward, however, we need to make sure that we are all as good as our word. If we say that things will be assessed on a case-by-case basis, they must be. When I remove myself from the national picture, which I never intended to be involved in, and go back to representing my constituents first and foremost, although perhaps not exclusively, I hope that each time an issue comes up and I take it to the Government, they will be as accommodating as they suggest they will.

I know that everyone is talking about the insurers, which I spoke about in one of my first speeches on the Fire Safety Bill. In a way, I am really pleased that we are all fed up with talking about the insurers, because if we are all talking about them, hopefully the Government will hear us. We think—and it is not an unreasonable position—that insurers should be part of this. As the Chairman of the Select Committee said, when the ABI was in front of the Committee it said that some of these premiums were helping them to put money aside in the event that they would need to pay in future. The way I look at it, they think they will have to do something anyway, so let us make sure that they are involved.

Peter Bottomley Portrait Sir Peter Bottomley
- Hansard - -

May I suggest that it would be a good idea if the Government had a roundtable with the insurers about what informal provision they are making in case there are successful actions, and about whether they would like voluntarily to contribute, say, £4 billion to £5 billion? No residential leaseholder would then carry the cost, and the insurance company would know that it would not be chased with legal claims that were likely to succeed.

Royston Smith Portrait Royston Smith
- Hansard - - - Excerpts

That is an excellent suggestion. The Government have been very successful in talking to developers and persuading them to sign up voluntarily, and there is no reason why they could not have similar conversations with insurers.

I do not want to make a case in defence of developers. I have made the case throughout that they should pay, but we need to be a bit careful about the possible unintended consequences of only going after them. I am pleased to note that they are taking responsibility for their own buildings, although they should have done that in the first place and they are a bit late to the party. Asking them then to remediate buildings that are not their responsibility will have all sorts of effects, not least in making them think about whether they will want to be in that particular market any more. I doubt that they will ever withdraw from the house building market, because it is their business, but if we want to ensure that we can build 300,000 homes a year—a proportion of which would, I am sure, be high-rise—we should bear in mind that some developers will now be saying, “This may not be for us in the future.”

I promised that I would not speak for too long, because we want to get through this business as quickly as possible, so I will end my comments by thanking the Minister again for what he has done and welcoming the changes that have been made. Given the Minister’s assurances today, I will be supporting the Government.

--- Later in debate ---
Stuart Andrew Portrait Stuart Andrew
- Hansard - - - Excerpts

Yes. I think I am correct in saying that. Yes, I am; I have just double-checked.

Colleagues have mentioned the 11-metre rule, and I reiterate that they should please write to my Department if they are aware of buildings under 11 metres that are facing costly remediation. We are clear that costly remediation should not be undertaken on buildings under 11 metres, and we would be glad to look into specific cases and to question freeholders on why they are insisting on commissioning costly and unnecessary remediation works.

In answer to my hon. Friend the Member for Worthing West (Sir Peter Bottomley), let me say that we are retrospectively extending the limitation period under section 1 of the Defective Premises Act. The duty under the Act applies to those taking on work in connection with the provision of a dwelling, which includes architects and contractors whose actions have contributed towards defects, as well as developers.

Peter Bottomley Portrait Sir Peter Bottomley
- Hansard - -

As I understand it, the difficulty is that a claim would need to be made on behalf of leaseholders by their landlord, who would insist on indemnity funding. The Minister and his advisers should get together with the Law Officers to find a practical way to ensure that claims to have a prospect of getting people to pay up, rather than people trying to resist. After Tony Pidgley sadly died, the new bosses resisted paying up to put right the defects in the Worcester Park block. That situation needs to be challenged.

Stuart Andrew Portrait Stuart Andrew
- Hansard - - - Excerpts

It is always wise for a Minister answering the Father of the House to take his sage advice, and of course I will speak to my officials.

The hon. Member for St Albans (Daisy Cooper) asked about valuations. I am aware there has been a discussion about how the Bill proposes to assess the value and banding of individual flats. The process set out in the Bill—further detail will be set out in regulations—takes the last price at which a flat changed hands, which will be recorded at the Land Registry, and uprates it in line with the national house price data produced by the Office for National Statistics. We recognise that this may produce a value that differs from the flat’s current market value, but we are using this approach for two specific reasons. First, it uses publicly available data and so avoids any potential for gaming the system. Secondly, it avoids the need to value a large number of flats individually, which would likely be both expensive and time-consuming and could delay the needed changes and improvements to those properties.